Terms & Conditions
Welcome to PerfectHome. By accessing or using our website and services, you agree to be bound by the following Terms & Conditions. Please read them carefully. If you do not agree with any part of these terms, you should not use our services.
1. Introduction
These Terms & Conditions govern your use of the website https://theperfecthome.in/ and all services provided by PerfectHome. We reserve the right to update or modify these terms at any time without prior notice.
2. Services Offered
PerfectHome provides professional services including but not limited to:
Dampness Rectification
Building Planning & Designing
Interior Works of Buildings
Structural Strengthening
Plumbing Renovation
Anti-Termite Treatment
Soil Testing & Recommendations
Piling Design & Execution
Railway and Road Over Bridge Construction
Project Surveying and Supervision
Miscellaneous Technical Services
The scope and execution of these services are defined in client-specific agreements or work orders.
3. User Responsibilities
By using our services, you agree to:
Provide accurate and complete information
Not misuse our services or website in any way
Comply with all applicable laws and regulations
Respect the intellectual property rights of PerfectHome and third parties
4. Payment Terms
Payment terms will be defined in each service agreement or quotation. Unless stated otherwise:
A deposit may be required before work begins
Full payment must be made upon completion or as per agreed milestones
Late payments may incur additional fees
5. Cancellations & Refunds
Cancellations must be made in writing. Refunds, if applicable, will be processed according to the terms outlined in the signed agreement. Partial work or completed services may not be eligible for refunds.
6. Intellectual Property
All content on our website, including text, logos, graphics, and service descriptions, is the property of PerfectHome and protected by intellectual property laws. You may not copy, reproduce, or distribute any content without written permission.
7. Limitation of Liability
While we strive to provide high-quality and reliable services, PerfectHome is not liable for:
Any indirect, incidental, or consequential damages
Losses resulting from project delays due to factors beyond our control
Damage caused by third-party contractors not affiliated with us
8. Confidentiality
We respect your privacy and confidentiality. Any sensitive project details or client information shared with us will be protected and not disclosed to third parties without your consent, unless required by law.
9. Governing Law
These Terms & Conditions are governed by the laws of [Insert Jurisdiction, e.g., India]. Any disputes will be resolved in the courts of [Insert City/Court Location].
10. Contact Us
If you have any questions regarding these Terms & Conditions, please contact us at:
PerfectHome
📍 [76/A, North road kolkata]
📧 [Insert Email Address]
📞 [+91 9279787107]